See tabs for “history”, “text”, “actions”, “authors”, “captions”, and “bill stages”.
here's the text of the bill:
By: Thompson H.B. No. 3182
A BILL TO BE ENTITLED
relating to consumer protection for and remedies available to a homebuyer whose home does not comply with certain warranties; providing an administrative penalty.
BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF TEXAS:
SECTION 1. Title 4, Property Code, is amended by adding Chapter 30 to read as follows:
CHAPTER 30. TEXAS HOMEBUYER PROTECTION ACT
Sec. 30.001. SHORT TITLE. This chapter may be cited as the Texas Homebuyer Protection Act.
Sec. 30.002. DEFINITIONS. In this chapter:
(1) "Administrator" means the administrator of the Texas Real Estate Commission.
(2) "Commission" means the Texas Real Estate Commission.
(3) "Contractor" means a person who, for compensation, engages in the construction, remodeling, repair, modification, or improvement of a building or a portion of a building used primarily for residential purposes.
(4) "Defect" means a condition that prevents a home from conforming to a contractor's warranty, including a warranty described by Section 30.008(c) or any other warranty provided by law.
(5) "Home" means a single-family house, duplex, triplex, or quadruplex or a unit in a multiunit structure used for residential purposes that is used or intended to be used as a dwelling by one of the owners.
(6) "Homebuyer" means a person who:
(A) purchased a home from a contractor and is entitled to enforce the terms of a contractor's warranty with respect to the home;
(B) is a lessor or lessee, other than a sublessee, who purchased or leased the home from a contractor; or
(C) is a transferee or assignee of a person described by Paragraph (A) or (B) if the transferee or assignee is a resident of this state and entitled to enforce the terms of a contractor's warranty.
(7) "Serious safety hazard" means a life-threatening malfunction, installation defect, or nonconformity that substantially impedes a person's ability to live in or use a home or that creates a substantial risk of fire, explosion, or exposure to a toxic substance.
(8) "Warranty" means an express or implied warranty.
Sec. 30.003. APPLICABILITY OF CERTAIN OTHER LAW OR CONTRACT PROVISIONS. (a) This chapter supersedes any other law or contract provision that conflicts with this chapter.
(b) The remedies provided by this chapter supersede remedies available under Chapter 27 or Title 16.
(c) Except as provided by this section, this chapter does not limit the rights or remedies otherwise available to a homebuyer under any other law.
(d) A contract provision that excludes or modifies the remedies provided by this chapter is prohibited and is void as against public policy unless the exclusion or modification is included in a settlement agreement between a homebuyer and a contractor.
Sec. 30.004. COMPLAINT. A homebuyer may seek a remedy provided by this chapter by:
(1) providing to the contractor written notice identifying each defect in the home that is covered by the contractor's warranty; and
(2) filing a complaint with the commission that includes a copy of the notice provided under Subdivision (1) on or before the 30th day after the date the notice is provided.
Sec. 30.005. HEARING. (a) The administrator may set a hearing on any allegation in a complaint that is not privately resolved between the homebuyer and the contractor.
(b) The contested case provisions of Chapter 2001, Government Code, apply to a hearing conducted under this chapter.
Sec. 30.006. TIME FOR FILING COMPLAINT. (a) Except as provided by Subsection (b), a homebuyer must file a complaint under this chapter before the earlier of:
(1) the date the express warranty period expires; or
(2) the 10th anniversary of the closing date.
(b) A homebuyer may file a complaint to which Section 30.010 applies on or before the 10th anniversary of the closing date.
Sec. 30.007. AFFIRMATIVE DEFENSE. In a hearing before the administrator under this chapter, a contractor may assert as an affirmative defense to an allegation of a defect made in a complaint filed under this chapter that the defect is the result of abuse, neglect, or modifications or alterations of the home made by a person other than the contractor.
Sec. 30.008. REPAIR REQUIRED. (a) Except as provided by Section 30.010, if a defect exists, the contractor shall make the repairs necessary to conform the home to the contractor's warranties if:
(1) the homebuyer or the homebuyer's designated agent reported the defect to the contractor or the contractor's agent before the expiration of the applicable time limit under Section 30.006; or
(2) a breach of a warranty described by Subsection (c) on the home is established.
(b) The contractor must make the repairs required under Subsection (a) not later than the 120th day after the date the notice of the defect required by Section 30.004 is received by the commission.
(c) Notwithstanding any other law, there is a presumption that a breach of a warranty on a home exists if the home does not comply with:
(1) a building code applicable to the home;
(2) the version applicable in the jurisdiction in which the home is constructed of:
(A) the International Building Code for One- and Two-Family Dwellings;
(B) the National Electric Code for One- and Two-Family Dwellings; or
(C) the manufacturer's specific installation instructions for the part or component used in construction of the home; or
(3) structural engineering standards or practices intended to prevent structural damage or a decrease in the market value of the home resulting from the failure of the foundation or other load-bearing portions of the home, including standards or practices used to ensure that a foundation is structurally sufficient without artificial moisture controls or other extraordinary maintenance by the homeowner.
Sec. 30.009. RETURN OR REPLACEMENT REQUIRED. (a) Except as provided by Section 30.010, if the contractor is unable to cure a defect within the period prescribed by Section 30.008(b) and the defect creates a serious safety hazard, substantially impairs the use of the home, or decreases the home's market value by more than five percent, the contractor shall at the homebuyer's option:
(1) replace the home with a comparable home in the same neighborhood; or
(2) accept return of the home from the homebuyer and refund to the homebuyer the full purchase price and any closing costs and reasonable moving costs.
(b) The administrator may not order a remedy under this section unless the contractor has been provided at least the number of days prescribed by Section 30.008(b) to cure the defect that is subject to the remedy provided by this section. The period required by this subsection is extended by the amount of time during which repair services are not available to a homebuyer because of a war, invasion, strike, or fire, flood, or other natural disaster.
Sec. 30.010. MOLD CONTAMINATION. (a) Not later than the 30th day after the date of the administrator's order of a remedy under this section, the contractor shall accept return of the home from the homebuyer and refund to the homebuyer the full purchase price and any closing costs and moving costs if, in addition to a notice of a defect required by Section 30.004, a homebuyer:
(1) provides to the contractor and the commission written results of tests that:
(A) are conducted by a mold testing laboratory certified for the purposes of this section; and
(B) demonstrate proof of unacceptable levels of toxic mold contamination that pose an imminent threat to the health, safety, or welfare of the inhabitants; and
(2) establishes that the contamination arises out of the defect.
(b) The commission by rule shall designate at least one private organization that certifies mold testing laboratories from whom certification is sufficient for the purposes of this section.
Sec. 30.011. REIMBURSEMENT OF EXPENSES. (a) If a contractor is ordered to replace a home or refund the purchase price under Section 30.009 or 30.010, the contractor shall reimburse the homebuyer for:
(1) reasonable incidental costs resulting from the loss of the use of the home because of the defect; and
(2) lost wages resulting from time required for appointments with the contractor or the contractor's representative that are necessary because of the defect.
(b) As necessary to promote the public interest, the commission by rule:
(1) shall define the incidental costs that are eligible for reimbursement under Subsection (a) and specify other requirements necessary to determine an eligible cost; and
(2) may set a maximum amount that is eligible for reimbursement, either by type of eligible cost or by a total for all costs.
(c) Refunds shall be made to the homebuyer and primary lienholder, as applicable.
Sec. 30.012. OTHER REMEDIES NOT PRECLUDED. This chapter does not prevent a homebuyer from obtaining a remedy available to the homebuyer under a new home warranty that provides remedies in addition to those provided by this chapter.
Sec. 30.013. RIGHT TO FILE ACTION. (a) Except as provided by this section, a homebuyer may not seek the remedies provided by this chapter in a civil action unless the homebuyer files a complaint against the contractor under this chapter and exhausts the administrative proceedings provided by this chapter. A court shall dismiss an action filed in violation of this section.
(b) If the hearing examiner does not issue a proposal for decision and make a recommendation to the administrator for a final order on or before the 150th day after the date a complaint is filed under this chapter, the administrator shall provide written notice, by certified mail, to the complainant and the contractor.
(c) The notice must inform the recipient of:
(1) the date the period for issuing a final order under this chapter expires; and
(2) the complainant's right to file an action under this section.
(d) After receiving a notice of the right to file an action under Subsection (b), a complainant may file an action against a contractor named in the complaint. The administrator's failure to issue a notice of the right to file an action does not affect a complainant's right to bring an action under this section.
Sec. 30.014. JUDICIAL REVIEW. A final order of the administrator under this chapter:
(1) is the final action of the commission under this chapter; and
(2) is subject to review only by judicial review as provided by Chapter 2001, Government Code, to the extent that chapter is not inconsistent with this chapter.
Sec. 30.015. INITIATION OR REMOVAL OF ACTION. (a) Except as otherwise provided by this chapter, an appeal initiated under this chapter may be removed to the Third Court of Appeals District if any party to the action files a notice of removal with the district court before the trial in the district court begins.
(b) An appeal initiated in or removed to the Third Court of Appeals District:
(1) must be initiated under Chapter 2001, Government Code, as if initiated in a Travis County district court; and
(2) is governed from the time of filing by the Texas Rules of Appellate Procedure.
(c) If evidence outside the commission's record is to be admitted in an appeal under Chapter 2001, Government Code, or otherwise, the action:
(1) must be initiated in a Travis County district court; or
(2) if initiated in the Third Court of Appeals District, is subject to remand to a Travis County district court for proceedings in accordance with instructions from the court of appeals.
(d) Citation must be served on the administrator and each party of record before the commission. For an appeal initiated in the Third Court of Appeals District, the court shall cause citation to be issued.
Sec. 30.016. DILIGENCE REQUIRED. (a) An appellant must pursue an appeal with reasonable diligence. If an appellant fails to prosecute an appeal in the six-month period after the appeal is filed, the court shall presume that the appeal has been abandoned and dismiss the appeal if a motion for dismissal is submitted by the attorney general or another party.
(b) An appeal may not be dismissed under this section if the appellant, after receiving notice and an opportunity to be heard, demonstrates good cause for a delay.
Sec. 30.017. DISCLOSURE REQUIRED. (a) A contractor that is ordered to refund the purchase price of or replace a home under this chapter shall provide to the first retail purchaser of the home after the home was repurchased or replaced by the contractor a disclosure statement stating that the home was repurchased or replaced by the contractor under this chapter.
(b) The disclosure statement must include the toll-free telephone number established by the commission under Section 30.019.
(c) Before a home repurchased or replaced under this chapter may be sold again, the deed that transfers title to the home must be marked with a clear statement that indicates that the home was repurchased or replaced under this chapter.
Sec. 30.018. RESTORATION OF WARRANTY REQUIRED. A contractor who sells a home after repurchasing or replacing the home under this chapter must:
(1) restore the home in a manner that conforms with applicable building codes; and
(2) issue an express warranty for the home.
Sec. 30.019. TOLL-FREE TELEPHONE NUMBER. The commission shall establish a toll-free telephone number for providing information to persons who request information about a defect that was the basis for ordering a remedy under this chapter. The commission shall maintain an effective method of providing information to persons who make requests.
Sec. 30.020. ANNUAL REPORT. (a) The commission shall publish and make available to the public an annual report relating to homes ordered repurchased or replaced by a contractor under this chapter.
(b) The report must:
(1) list the number of homes by subdivision name, if any;
(2) identify the contractor; and
(3) include a brief description of each defect that was the subject of a remedy provided by this chapter.
(c) The commission may charge a reasonable fee to recover the cost of the report.
Sec. 30.021. ADMINISTRATIVE PENALTY. (a) The commission may impose an administrative penalty on a person who violates this chapter or a rule or order adopted under this chapter.
(b) The imposition of a penalty is governed by Subchapter O, Chapter 1101, Occupations Code.
Sec. 30.022. RULES. The commission, in consultation with the Texas Real Estate Inspector Committee, shall adopt rules necessary for the enforcement and administration of this chapter.
SECTION 2. (a) This Act takes effect September 1, 2009.
(b) This Act applies only to the sale of a new home for which the closing date is on or after September 1, 2009. A sale of a new home for which the closing date was before September 1, 2009, is governed by the law in effect at the time of the sale, and that law is continued in effect for that purpose.